Terms & Conditions

1. Agreement to Terms

These Terms and Conditions ("Terms") constitute a legally binding agreement between you and Home Wings Interiors ("Company," "we," "our," or "us") regarding your use of our website homewingsinteriors.com and our interior design services.

By accessing our website or using our services, you agree to be bound by these Terms. If you do not agree to these Terms, please do not use our website or services.

2. Description of Services

Home Wings Interiors provides professional interior design services including but not limited to:

• Full-service interior design
• E-design consultation services
• Space planning and layout design
• Color consultation
• Furniture sourcing and procurement
• Lighting design
• Home staging services
• Seasonal decorating

Specific service details, timelines, and deliverables will be outlined in individual service agreements or proposals.

3. Service Agreements and Contracts

All design services require a signed service agreement that will include:

• Scope of work and deliverables
• Project timeline and milestones
• Payment terms and schedule
• Client responsibilities
• Revision and approval processes

The service agreement, together with these Terms, constitutes the complete agreement between you and Home Wings Interiors for the provision of services.

4. Payment Terms

Payment Schedule

Payment terms vary by service type and will be specified in your service agreement. Generally:

• E-design services: Full payment due upon booking
• Consultation services: Payment due at time of service
• Full-service projects: Typically 50% deposit, with remaining balance due upon completion
• Home staging: Payment due before installation

Accepted Payment Methods

We accept major credit cards, bank transfers, and checks. All payments must be in US dollars.

Late Payments

Late payments may result in project delays and may incur additional fees as specified in your service agreement.

5. Client Responsibilities

To ensure successful project completion, clients are responsible for:

• Providing accurate measurements and property information
• Timely communication and feedback
• Making decisions within agreed timeframes
• Providing access to the property as needed
• Obtaining necessary permits or approvals
• Ensuring property is ready for installation/staging
• Payment according to agreed schedule

6. Intellectual Property

Design Concepts

All design concepts, plans, drawings, and specifications created by Home Wings Interiors remain our intellectual property until full payment is received. Upon full payment, you receive a license to use the designs for the specified project.

Portfolio Use

We reserve the right to photograph completed projects and use images for marketing, portfolio, and promotional purposes unless otherwise agreed in writing.

Website Content

All content on our website, including text, graphics, logos, and images, is protected by copyright and other intellectual property laws.

7. Cancellation and Refund Policy

Client Cancellation

Cancellation policies vary by service type:

• Consultations: 24-hour cancellation notice required for full refund
• E-design: Cancellation before work begins: full refund minus processing fees
• Full-service projects: Cancellation terms specified in service agreement
• Home staging: 48-hour cancellation notice required

Company Cancellation

We reserve the right to cancel services in cases of non-payment, breach of terms, or other circumstances that prevent successful project completion.

8. Limitation of Liability

Home Wings Interiors's liability is limited to the amount paid for services. We are not liable for:

• Indirect, incidental, or consequential damages
• Delays caused by factors beyond our control
• Third-party contractor performance
• Product defects or manufacturer issues
• Changes in product availability or pricing
• Damage to existing property during installation

9. Force Majeure

We are not liable for delays or inability to perform due to circumstances beyond our reasonable control, including but not limited to natural disasters, government actions, labor disputes, or supply chain disruptions.

10. Product Procurement and Installation

Product Sourcing

When we source products on your behalf:

• We act as your agent in purchasing
• You are responsible for all product costs
• Product warranties are between you and the manufacturer
• We are not responsible for product defects or delays

Installation Services

Installation services are provided by qualified third-party contractors. We coordinate but do not directly provide installation services.

11. Confidentiality

We respect your privacy and will maintain confidentiality of your personal information and project details. We will not share your information with third parties except as necessary to provide services or as required by law.

12. Website Use

Permitted Use

You may use our website for lawful purposes only. You agree not to:

• Violate any applicable laws or regulations
• Infringe on intellectual property rights
• Transmit harmful or malicious content
• Attempt to gain unauthorized access
• Use automated systems to access the site

User Content

By submitting content to our website (reviews, comments, images), you grant us a non-exclusive license to use, modify, and display such content for business purposes.

13. Dispute Resolution

Governing Law

These Terms are governed by the laws of the State of New York, United States, without regard to conflict of law principles.

Dispute Resolution Process

Any disputes will be resolved through:

1. Good faith negotiation
2. Mediation if negotiation fails
3. Binding arbitration if mediation fails

Jurisdiction

Any legal proceedings must be brought in the courts of New York County, New York.

14. Warranties and Disclaimers

Service Warranty

We warrant that our services will be performed with professional skill and care. Our sole obligation for any breach of this warranty is to re-perform the deficient services.

Disclaimers

Except as expressly stated, we provide services "as is" without warranties of any kind. We disclaim all implied warranties including merchantability and fitness for a particular purpose.

15. Indemnification

You agree to indemnify and hold harmless Home Wings Interiors from any claims, damages, or expenses arising from your breach of these Terms or your use of our services.

16. Modifications to Terms

We reserve the right to modify these Terms at any time. Updated Terms will be posted on our website with a new effective date. Your continued use of our services after changes constitutes acceptance of the modified Terms.

17. Severability

If any provision of these Terms is found to be unenforceable, the remaining provisions will continue in full force and effect.

18. Entire Agreement

These Terms, together with any signed service agreements, constitute the entire agreement between you and Home Wings Interiors regarding the use of our website and services.

19. Contact Information

If you have any questions about these Terms, please contact us:

20. Acknowledgment

By using our website or services, you acknowledge that you have read, understood, and agree to be bound by these Terms and Conditions.